1. Acceptance of Terms
By accessing or using this website, requesting an estimate, scheduling an appointment, or
booking a home service, you agree to be bound by these Terms and Conditions and the
applicable Privacy Policy. If you do not agree with these terms, please do not use the
website or request services through it.
2. Website Use
The website is provided to give information about available home services, allow customers to
submit inquiries, request estimates, schedule services, and communicate about service needs.
You agree to use the website only for lawful purposes and not to interfere with its
operation, security, or availability.
3. Service Agreements
Individual home services may be subject to a separate written estimate, work order, proposal,
or service agreement. That document may describe the specific work to be performed,
materials, pricing, expected schedule, payment terms, warranties, exclusions, and other
project requirements.
If there is a conflict between these website terms and a signed service agreement, the
applicable service agreement may control with respect to that specific service.
4. Service Requests and Estimates
Submitting a service request through the website does not automatically create a binding
service agreement. Requests may need to be reviewed before a service, appointment, or
estimate is confirmed.
Estimates are based on the information available at the time they are prepared and may change
if the scope of work, site conditions, materials, labor requirements, or other relevant
circumstances change.
5. Customer Responsibilities
You agree to provide accurate and complete information regarding the requested service and
property. You are responsible for providing reasonable access to the areas where work is
scheduled and for informing us of relevant conditions that could affect the work.
You should also remove or secure valuable, fragile, or personal belongings from work areas
when reasonably necessary.
6. Property Conditions
Existing property conditions, hidden damage, structural issues, inaccessible areas, outdated
installations, code requirements, or other conditions that could not reasonably be
identified before work begins may require additional work, materials, time, or cost.
Where practical, we will notify you before performing additional work that materially changes
the agreed scope.
7. Pricing and Payment
Prices, deposits, balances, taxes, material charges, and other applicable costs will be
communicated through the applicable estimate or service agreement. Unless otherwise stated,
payment is due according to the payment schedule established for the service.
Unpaid or overdue balances may result in delayed scheduling, suspension of work, cancellation
of future appointments, or other remedies permitted by the applicable agreement and law.
8. Changes to the Scope of Work
Requests for additional work, substitutions, upgrades, or changes to the original scope may
result in additional charges or changes to the schedule. Additional work may require
customer approval before it begins.
Changes may also affect previously provided estimates, completion dates, material
requirements, and other project conditions.
9. Scheduling and Appointments
Appointment times and estimated completion dates are provided in good faith but may change
due to weather, material availability, permitting, property access, emergencies, supplier
delays, or other circumstances beyond reasonable control.
We will make reasonable efforts to communicate significant scheduling changes and work with
customers to arrange an alternative time when necessary.
10. Cancellations and Rescheduling
Customers may be required to provide reasonable notice when cancelling or rescheduling an
appointment. Certain cancellations may be subject to charges for materials already
purchased, special-order items, completed work, reserved labor, or other costs identified in
the applicable service agreement.
11. Materials and Product Availability
Materials selected for a project may be subject to availability, supplier limitations,
discontinued products, shipping delays, or other circumstances outside our control. When
necessary, a comparable alternative may be proposed for approval.
Manufacturer warranties, when applicable, are subject to the manufacturer's own terms and
conditions.
12. Workmanship
Services will be performed with reasonable care and skill consistent with the applicable
service agreement. Any workmanship guarantee or warranty will be governed by the written
terms provided for the specific service.
Warranty coverage may not apply to damage caused by misuse, neglect, unauthorized
modifications, normal wear and tear, third-party work, or conditions outside the agreed
scope.
13. Permits and Approvals
Certain home improvement or repair services may require permits, inspections, homeowner
approvals, property-owner authorization, or compliance with applicable building
requirements. Responsibility for obtaining such approvals will be determined by the
applicable service agreement.
14. Customer-Provided Materials
If you provide materials, fixtures, equipment, appliances, or other products for
installation, we are not responsible for defects, incompatibility, missing components,
manufacturer issues, or delays caused by those items unless otherwise agreed in writing.
15. Access and Safety
You agree to provide a reasonably safe working environment and disclose known hazards that
could affect personnel, equipment, or the performance of the service. Work may be delayed or
refused when conditions present an unreasonable safety risk.
16. Pets and Personal Belongings
Customers are responsible for securing pets and protecting personal belongings in or near
work areas. We may request that pets or other items be moved before work begins when
reasonably necessary for safety or access.
17. Third-Party Services
Some services may involve independent suppliers, manufacturers, subcontractors, delivery
providers, payment processors, or other third parties. Their services may be subject to
separate terms, warranties, or policies.
Where third parties are involved, their applicable terms may apply to the portion of the
service they provide.
18. Photos and Documentation
Photographs, measurements, notes, invoices, service records, and other documentation may be
created or retained when reasonably necessary to estimate, perform, document, or support a
service.
Customers should not provide photographs containing unnecessary sensitive personal
information.
19. Website Content
Information, descriptions, images, service details, pricing examples, and other content
displayed on the website are provided for general informational purposes. We make reasonable
efforts to keep information accurate but do not guarantee that all website content will
always be complete, current, or error-free.
20. Intellectual Property
Website content, including text, graphics, photographs, logos, layouts, designs, icons, and
other materials, may be protected by intellectual property laws. You may not reproduce,
distribute, modify, or commercially use website content without appropriate authorization.
21. Prohibited Activities
You may not use the website to submit false information, impersonate another person,
interfere with website security, introduce malicious software, attempt unauthorized access,
scrape or misuse website content, or otherwise engage in activity that could damage the
website or other users.
22. Limitation of Liability
To the maximum extent permitted by applicable law, liability arising from a specific service
will be limited to the amount paid for that service, except where a different limitation is
required by law. Nothing in these terms is intended to exclude liability that cannot legally
be excluded or limited.
23. Delays and Events Beyond Our Control
We are not responsible for delays or inability to perform caused by circumstances reasonably
beyond our control, including severe weather, natural disasters, utility interruptions,
transportation problems, supply shortages, government actions, labor disruptions,
emergencies, or unexpected property conditions.
24. Ending or Suspending Services
Either party may end or suspend a service agreement when permitted by the applicable
agreement or law. Customers remain responsible for payment for work completed, approved
materials purchased, non-refundable charges, and other amounts properly due before
termination.
25. Disputes
If a dispute arises regarding a service, the parties should first make a reasonable effort to
communicate and resolve the matter. Any formal dispute process, jurisdiction, venue,
mediation, arbitration, or other requirement will be governed by the applicable service
agreement and applicable law.
26. Privacy
Information submitted through the website or in connection with our services is handled
according to the applicable Privacy Policy. By using the website or requesting services, you
acknowledge that you have reviewed the Privacy Policy.
27. Changes to These Terms
These Terms and Conditions may be updated from time to time to reflect changes in services,
website functionality, business practices, or legal requirements. Updated terms will be made
available through the website.
28. Severability
If any provision of these terms is determined to be invalid, unlawful, or unenforceable, that
provision will be limited or removed to the extent necessary, while the remaining provisions
will continue to apply to the fullest extent permitted by law.
29. Entire Agreement
These Terms, together with any applicable estimate, proposal, work order, service agreement,
Privacy Policy, and other written terms provided for a specific service, constitute the
applicable understanding between the parties regarding the services requested.
30. Governing Law
These Terms and Conditions will be interpreted and enforced according to the laws applicable
to the service transaction and the jurisdiction in which the applicable service is provided,
unless a separate written agreement states otherwise.